The Turnkey Contract Agreement is a sophisticated legal instrument used in Danish construction projects where a single contractor takes full responsibility for both design and construction aspects. This document is particularly relevant when project owners seek a simplified contractual relationship with a single point of responsibility for project delivery. It incorporates key elements of Danish construction law, including ABT 18 principles, building regulations, and environmental requirements. The agreement is structured to cover all aspects of project execution, from initial design through to commissioning and warranties, making it suitable for complex construction projects where complete transfer of project delivery responsibility to the contractor is desired. The document includes detailed provisions for risk allocation, payment mechanisms, quality control, and dispute resolution, all aligned with Danish legal requirements and industry standards.
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership of your information
Key Requirements PROMPT example:
Turnkey Contract Agreement
I need a Turnkey Contract Agreement under Danish law for the construction of a renewable energy facility in Copenhagen, with project completion scheduled for December 2025, including specific provisions for environmental compliance and technology performance guarantees.
1. Parties: Identification and details of the Employer and the Contractor, including their legal representatives
2. Background: Context of the agreement, project overview, and basis for the contract
3. Definitions: Definitions of key terms used throughout the agreement
4. Scope of Works: Detailed description of the works to be performed, including design and construction obligations
5. Contract Documents: Hierarchy and list of contract documents, including drawings, specifications, and standards
6. Contractor's Obligations: Comprehensive list of contractor's responsibilities including design, construction, testing, and commissioning
7. Employer's Obligations: Employer's responsibilities including site access, permits, and information provision
8. Time for Completion: Project schedule, milestones, completion dates, and extension mechanisms
9. Contract Price and Payment: Price structure, payment terms, variations, and payment procedures
10. Quality and Standards: Quality requirements, applicable standards, and inspection procedures
11. Testing and Commissioning: Requirements for testing, commissioning, and performance verification
12. Taking Over: Procedures for completion, taking over, and acceptance of the works
13. Defects Liability: Warranty period, defects correction, and maintenance obligations
14. Risk and Insurance: Risk allocation, required insurance coverage, and liability provisions
15. Force Majeure: Definition and consequences of force majeure events
16. Variations: Procedures for changes to the works and their impact on price and time
17. Suspension and Termination: Rights and procedures for suspension and termination of the contract
18. Dispute Resolution: Procedures for dispute resolution, including mediation and arbitration
19. Governing Law: Specification of Danish law as governing law and jurisdiction
20. General Provisions: Miscellaneous provisions including notices, assignments, and amendments
1. Performance Security: Requirements for performance bonds or guarantees, used when additional financial security is required
2. Intellectual Property Rights: Provisions regarding IP rights and licenses, particularly relevant for projects involving significant design elements or innovative solutions
3. Environmental Requirements: Specific environmental obligations and compliance requirements, important for projects with significant environmental impact
4. Health and Safety: Detailed health and safety requirements, particularly important for high-risk construction projects
5. Local Content Requirements: Provisions for local content or resources, relevant when required by local regulations or project specifics
6. Interface Management: Procedures for managing interfaces with other contractors or stakeholders, relevant for complex projects with multiple contractors
7. Training and Technology Transfer: Requirements for training employer's personnel and technology transfer, relevant for complex technical facilities
8. Advance Payment: Terms and conditions for advance payments, used when advance funding is required
1. Schedule 1 - Scope of Works: Detailed technical specifications and scope description
2. Schedule 2 - Site Information: Site details, geological data, and existing conditions
3. Schedule 3 - Time Schedule: Detailed project schedule with milestones and completion dates
4. Schedule 4 - Payment Schedule: Payment terms, milestones, and procedures
5. Schedule 5 - Key Personnel: List of key personnel from both parties with roles and responsibilities
6. Schedule 6 - Forms of Guarantees: Ƶ for various guarantees and bonds
7. Schedule 7 - Testing and Commissioning Requirements: Detailed testing and commissioning procedures and acceptance criteria
8. Schedule 8 - Permits and Approvals: List of required permits and responsible parties
9. Schedule 9 - Insurance Requirements: Detailed insurance requirements and coverage limits
10. Schedule 10 - Quality Assurance Requirements: Quality management procedures and requirements
11. Appendix A - Drawings: Complete set of contract drawings
12. Appendix B - Technical Specifications: Detailed technical specifications and standards
13. Appendix C - Environmental Management Plan: Environmental requirements and compliance procedures
Authors
Relevant legal definitions
Clauses
Relevant Industries
Construction
Infrastructure Development
Industrial Facilities
Energy and Power
Manufacturing Plants
Commercial Real Estate
Healthcare Facilities
Educational Institutions
Renewable Energy
Data Centers
Transportation
Waste Management Facilities
Water Treatment Plants
Relevant Teams
Legal
Commercial
Project Management
Construction
Design
Procurement
Finance
Risk Management
Quality Assurance
Environmental Compliance
Health and Safety
Operations
Technical Services
Contract Administration
Business Development
Relevant Roles
Project Director
Construction Manager
Contract Manager
Legal Counsel
Commercial Director
Chief Executive Officer
Technical Director
Procurement Manager
Risk Manager
Design Manager
Project Engineer
Quality Assurance Manager
Finance Director
Operations Director
Business Development Manager
Compliance Officer
Cost Controller
Site Manager
Environmental Manager
Health and Safety Manager
Find the exact document you need
Construction Business Partnership Agreement
Danish law-governed agreement establishing a partnership between construction industry entities, defining terms, obligations, and operational framework.
find out more
Agreement With Builder For (Construction)
Danish law-governed construction agreement between building owner and contractor, establishing terms for construction project execution and compliance with Danish building regulations.
find out more
Vesting Agreement (Construction)
A legal agreement governing progressive ownership transfer during construction projects under Danish law.
find out more
Build Agreement
Danish law construction contract establishing terms and conditions between employer and contractor under AB 18 framework.
find out more
Novation Agreement (Construction)
A Danish law agreement transferring rights and obligations under a construction contract from an original contractor/consultant to a new one, ensuring project continuity under Danish construction regulations.
find out more
Turnkey Project Agreement
Danish law-governed agreement for complete turnkey project delivery, covering design through commissioning with contractor's full responsibility for operational facility delivery.
find out more
Residential Contractor Agreement
A Danish law-governed agreement between a contractor and homeowner for residential construction or renovation works, incorporating Danish construction and consumer protection requirements.
find out more
Mural Agreement
Danish law-governed agreement for commissioning and installing mural artwork, defining rights and responsibilities between artists and property owners.
find out more
Project Hire Contract
Danish law-governed agreement for project-based employment, defining project scope, deliverables, and employment terms.
find out more
Pipeline Agreement
Danish law-governed agreement for pipeline construction, operation, and maintenance, incorporating local regulatory requirements and EU compliance measures.
find out more
Consortium Partnership Agreement
Danish law-governed agreement establishing and regulating a consortium partnership between multiple organizations, defining collaboration terms and governance structure.
find out more
Building Construction Agreement
Danish law-governed construction agreement establishing terms between building owner and contractor, incorporating AB 18 principles and local building regulations.
find out more
Project Alliance Agreement
A Danish law-governed collaborative agreement establishing a project alliance framework for joint project delivery with shared risks and rewards.
find out more
Project Delivery Agreement
Danish law-governed agreement establishing terms and conditions for project delivery, including scope, deliverables, and party obligations.
find out more
Pilot Project Agreement
Danish law agreement for establishing and governing pilot projects, including scope, responsibilities, and IP rights.
find out more
Minor Works Agreement
A Danish law-governed construction contract for small-scale building projects and renovations, incorporating key principles from Danish construction law and the AB-System.
find out more
Turnkey Contract Agreement
A Danish law-governed agreement for turnkey construction projects, establishing comprehensive terms for design-build project delivery under ABT 18 principles.
find out more
Commercial Supply Agreement
A Danish law-governed agreement establishing terms and conditions for regular commercial supply of goods between supplier and buyer.
find out more
Engineering Procurement And Construction Agreement
Danish law-governed agreement for comprehensive engineering, procurement, and construction projects, detailing contractor obligations and project execution requirements.
find out more
Project Cooperation Agreement
Danish law-governed agreement establishing terms and conditions for multi-party project collaboration, including responsibilities, resources, and rights.
find out more
Project Agreement Contract
Danish law-governed agreement establishing terms and conditions for project execution, including scope, deliverables, timelines, and responsibilities.
find out more
New Construction Agreement
Danish law-governed agreement for new construction projects, incorporating AB 18 requirements and establishing key terms between client and contractor.
find out more
Renovation Agreement
Danish law-governed agreement outlining terms and conditions for property renovation work, including scope, pricing, timeline, and responsibilities.
find out more
Demolition Agreement
Danish law-governed agreement setting terms and conditions for demolition works, including safety, environmental, and regulatory requirements.
find out more
Project Development Agreement
A Danish law-governed agreement between developer and client establishing terms and conditions for property or infrastructure development projects.
find out more
Proof Of Concept Agreement
A Danish law agreement governing the testing and evaluation of new technologies or solutions, establishing terms for proof of concept implementation.
find out more
Pre Construction Agreement
Danish law-governed agreement establishing terms and conditions for pre-construction services between client and contractor.
find out more
Download our whitepaper on the future of AI in Legal
By providing your email address you are consenting to our Privacy Notice.
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
Our bank-grade security infrastructure undergoes regular external audits
We are ISO27001 certified, so your data is secure
Organizational security
You retain IP ownership of your documents
You have full control over your data and who gets to see it
Innovation in privacy:
Genie partnered with the Computational Privacy Department at Imperial College London
Together, we ran a £1 million research project on privacy and anonymity in legal contracts
Want to know more?
Visit our for more details and real-time security updates.
Read our Privacy Policy.