The Construction Contractor Contract is a vital legal instrument used in Pakistan's construction industry to formalize the relationship between contractors and project owners. This document is essential when engaging a contractor for construction projects of any scale, from residential buildings to major infrastructure developments. It incorporates requirements from Pakistani legislation, including the Contract Act 1872, Building and Construction By-laws, and relevant environmental and safety regulations. The contract typically includes comprehensive details about project scope, payment terms, timelines, quality standards, and dispute resolution mechanisms. It serves as the primary reference document throughout the construction project, ensuring clarity in roles, responsibilities, and deliverables while providing legal protection for all parties involved.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Your data doesn't train Genie's AI
You keep IP ownership of your docs
1. Parties: Identification and details of the employer and contractor, including their legal status and registered addresses
2. Background: Context of the construction project and the purpose of the agreement
3. Definitions: Detailed definitions of terms used throughout the contract
4. Scope of Work: Detailed description of the construction work to be performed
5. Contract Price and Payment Terms: Amount payable, payment schedule, variations, and payment procedures
6. Timeline and Completion: Project schedule, milestones, completion dates, and provisions for delays
7. Contractor's Obligations: Key responsibilities including workmanship, materials, safety, and compliance
8. Employer's Obligations: Responsibilities including site access, permits, and approvals
9. Quality and Standards: Required quality standards, inspections, and approval processes
10. Materials and Equipment: Specifications for materials, procurement requirements, and equipment standards
11. Health and Safety: Safety requirements, procedures, and compliance with regulations
12. Insurance and Indemnities: Required insurance coverage and indemnification provisions
13. Variations and Changes: Procedures for handling changes to scope, price, or timeline
14. Defects and Warranties: Defect liability period, warranties, and remedial works
15. Termination: Grounds and procedures for contract termination
16. Dispute Resolution: Procedures for resolving disputes including arbitration provisions
17. Governing Law: Applicable law and jurisdiction
1. Performance Security: Requirements for performance bonds or guarantees, used for larger projects
2. Environmental Compliance: Specific environmental requirements, needed for projects with significant environmental impact
3. Local Content Requirements: Provisions for local material/labor usage, relevant for government or public sector projects
4. Force Majeure: Provisions for unforeseen circumstances, particularly important in long-term projects
5. Intellectual Property: IP rights provisions, relevant when design elements are involved
6. Confidentiality: Confidentiality obligations, important for sensitive or high-value projects
7. Assignment and Subcontracting: Rules for engaging subcontractors, relevant for complex projects
8. Testing and Commissioning: Detailed testing requirements, necessary for technical installations
9. Site Security: Security requirements, important for high-risk or sensitive locations
10. Advance Payment: Terms for advance payments, used when contractor requires initial funding
1. Schedule 1 - Technical Specifications: Detailed technical requirements and specifications for the construction work
2. Schedule 2 - Bill of Quantities: Itemized list of quantities and rates for the work
3. Schedule 3 - Project Timeline: Detailed project schedule with milestones and deadlines
4. Schedule 4 - Payment Schedule: Detailed breakdown of payment terms, installments, and milestone payments
5. Schedule 5 - Site Plan and Drawings: Construction drawings, site plans, and architectural designs
6. Schedule 6 - Quality Assurance Plan: Detailed quality control procedures and requirements
7. Schedule 7 - Health and Safety Plan: Detailed safety procedures and requirements
8. Schedule 8 - List of Approved Subcontractors: Pre-approved subcontractors and their scope of work
9. Schedule 9 - Forms and Certificates: Standard forms for variations, completion certificates, and other documentation
10. Schedule 10 - Insurance Requirements: Detailed insurance requirements and coverage levels
Find the exact document you need
Agreement Between Builder And Labour Contractor
A Pakistani law-governed agreement between builders and labor contractors defining terms for construction workforce services, including responsibilities, payments, and compliance requirements.
Download
Basic General Contractor Agreement
A Pakistani law-governed agreement between property owners and general contractors defining terms and conditions for construction projects.
Download
Cleaning Subcontractor Contract
A Pakistani law-governed agreement between a main contractor and cleaning subcontractor defining terms for cleaning service provision and operational requirements.
Download
Contract Between Employer And Contractor
A Pakistani law-governed agreement establishing terms and conditions between an employer and contractor, defining work scope, payments, and mutual obligations.
Download
Electrical Contractor Agreement
A Pakistani law-governed agreement between client and electrical contractor for electrical services, incorporating local regulatory requirements and industry standards.
Download
Contractor Service Contract
A Pakistani law-governed agreement establishing terms and conditions between a client and an independent contractor for the provision of specific services.
Download
Labour Contract Form
A legally binding employment agreement compliant with Pakistani labor laws that establishes terms and conditions between employer and employee.
Download
Contractor Agreement For House (Construction)
A Pakistani law-governed agreement between property owner and contractor for residential construction, detailing project scope, terms, and mutual obligations.
Download
Contractor Deposit Agreement
A Pakistan-compliant agreement governing contractor security deposits, their maintenance, and return conditions.
Download
Building Construction Labour Contract Agreement
A standardized labor contract agreement for construction workers in Pakistan, ensuring compliance with local labor laws and construction regulations.
Download
Home Contractor Contract
A Pakistani law-governed contract between homeowner and contractor for residential construction/renovation work, outlining project terms, obligations, and deliverables.
Download
Standard Independent Contractor Contract
A Pakistani law-governed agreement establishing an independent contractor relationship, defining services, payments, and obligations while ensuring legal compliance.
Download
Real Estate Contractor Agreement
A Pakistani law-governed agreement between property owner and contractor for construction works, detailing project terms, conditions, and regulatory compliance requirements.
Download
Agreement Between Owner And Electrical Contractor
A comprehensive contract governing electrical works between property owners and contractors in Pakistan, ensuring compliance with local regulations and safety standards.
Download
Standard Contractor Contract
A Pakistani law-governed agreement establishing terms and conditions between a company and an independent contractor, ensuring legal compliance while defining service scope and relationship parameters.
Download
Generic Contractor Agreement
A Pakistan-law compliant agreement establishing terms and conditions between a hiring entity and an independent contractor, covering work scope, payments, and legal obligations.
Download
Independent Service Contract
A Pakistani law-governed agreement establishing terms and conditions between an independent service provider and client, defining service scope, payments, and contractual obligations.
Download
Agreement Between Company And Labour Contractor
A legal agreement under Pakistani law governing the relationship between a company and labor contractor for workforce provision and management.
Download
Construction Agreement Form
A comprehensive construction agreement template compliant with Pakistani law, establishing terms and conditions between contractors and clients for construction projects.
Download
Freelance Contractor Agreement
A Pakistani law-compliant agreement establishing terms and conditions between a business and an independent contractor.
Download
Simple Subcontractor Agreement
A Pakistani law-governed agreement establishing terms and conditions between a main contractor and subcontractor for delegated work or services.
Download
Residential Contractor Agreement
A Pakistani law-governed agreement between property owner and contractor for residential construction works, detailing project scope, terms, and obligations.
Download
Labour Hire Contract
A Pakistani law-compliant agreement establishing terms for labor hire arrangements between a labor hire company, worker, and client company.
Download
Consulting Agreement Contract
A Pakistani law-governed agreement establishing terms and conditions between a consultant and client for professional consulting services.
Download
Construction Contractor Contract
A Pakistani law-governed agreement between a construction contractor and project owner, defining construction project terms, obligations, and execution requirements.
Download
Startup Contractor Agreement
A Pakistan-law governed contractor agreement for startups engaging independent professionals, ensuring legal compliance while maintaining startup-appropriate flexibility.
Download
Standard Builders Contract
A Pakistani law-governed construction agreement establishing rights and obligations between employer and contractor for building projects, aligned with local regulations and industry standards.
Download
Percentage Agreement Contract
A Pakistani law-governed agreement establishing percentage-based commercial relationships, detailing calculation methods and payment terms for revenue or profit sharing arrangements.
Download
Part Time Contractor Agreement
Pakistani law-compliant agreement establishing terms and conditions for part-time contractor engagement, including scope, payment, and legal obligations.
Download
Independent Employment Agreement
A Pakistani law-governed agreement establishing an independent contractor relationship between a company and a service provider, defining services, compensation, and compliance requirements.
Download
Home Remodel Contract
A Pakistani law-governed contract for home renovation projects between homeowners and contractors, outlining construction terms and obligations.
Download
Housekeeping Services Agreement Contract
A Pakistani law-governed agreement establishing terms and conditions for professional housekeeping services, including service scope, requirements, and compliance with local regulations.
Download
General Contract Agreement Between Two Parties
A standard bilateral contract agreement compliant with Pakistani law, establishing terms and conditions for business relationships between two parties.
Download
Construction Service Contract
A Pakistani law-governed agreement establishing terms and conditions for construction services between contractor and client, ensuring regulatory compliance and project delivery standards.
Download
Confidentiality Agreement For Contractors
A Pakistan-law governed agreement establishing confidentiality obligations between a company and its contractors, protecting sensitive business information and trade secrets.
Download
Agreement For Construction Of House
A Pakistani law-governed agreement establishing terms and conditions for residential house construction, including specifications, timelines, and payment terms.
Download
Agreement Between Contractor And Principal Employer
A Pakistan-law governed agreement establishing terms and conditions between a Principal Employer and Contractor for professional services.
Download
Truck Driver Contractor Agreement
A Pakistani law-governed agreement establishing terms and conditions between a company and an independent truck driver contractor, covering operational, safety, and compliance requirements.
Download
Contract Agreement Between Contractor And Client
A Pakistani law-governed agreement establishing terms and conditions between a client and contractor for professional services or project delivery.
Download
Hourly Independent Contractor Agreement
A Pakistani law-governed agreement establishing terms and conditions for hourly-based independent contractor services.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)