The Site Development Agreement is a crucial document used in Singapore when parties wish to formalize arrangements for developing land or property. It serves as the primary contract governing the development process, incorporating Singapore's strict building control and urban planning requirements. This agreement type is particularly important given Singapore's comprehensive regulatory framework for property development, including URA guidelines and environmental considerations. The Site Development Agreement typically includes detailed provisions about construction specifications, timelines, regulatory compliance, and risk allocation between parties.
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership of your information
Key Requirements PROMPT example:
Site Development Agreement
"I need a Site Development Agreement for a mixed-use development project in Singapore's Central Business District, with specific provisions for green building standards and heritage conservation requirements as the site includes a preserved shophouse."
1. Parties: Identification and details of the developer and landowner/client
2. Background: Context of the development, property details, and development objectives
3. Definitions: Key terms used throughout the agreement including technical, legal, and project-specific definitions
4. Scope of Development: Detailed description of the development works to be undertaken, including specifications and standards
5. Development Timeline: Project milestones, completion dates, and critical deadlines including consequences of delays
6. Development Obligations: Detailed responsibilities of each party during the development process, including compliance requirements
7. Approvals and Permits: Requirements for obtaining necessary governmental approvals and maintaining compliance
8. Payment Terms: Financial arrangements, development costs, payment schedule, and payment conditions
9. Insurance and Liability: Insurance requirements, indemnification provisions, and allocation of risks
10. Default and Termination: Events of default, remedies, and procedures for contract termination
11. Dispute Resolution: Procedures for resolving disputes, including mediation and arbitration provisions
12. General Provisions: Standard contractual provisions including notices, amendments, and governing law
1. Environmental Requirements: Environmental compliance obligations and mitigation measures for developments requiring environmental assessment
2. Heritage Conservation: Special requirements and restrictions for developments involving heritage buildings or conservation areas
3. Community Engagement: Requirements for community consultation and engagement processes for large-scale developments
4. Force Majeure: Provisions dealing with unforeseen circumstances and their impact on development obligations
5. Intellectual Property: Rights and obligations regarding design documents, plans, and other intellectual property
1. Schedule 1 - Site Plans and Drawings: Detailed technical drawings, site plans, and architectural designs
2. Schedule 2 - Development Specifications: Technical specifications, materials requirements, and quality standards
3. Schedule 3 - Payment Schedule: Detailed breakdown of payment milestones and payment amounts
4. Schedule 4 - Required Approvals: Comprehensive list of necessary permits, licenses, and regulatory approvals
5. Schedule 5 - Construction Timeline: Detailed project schedule with milestones and critical path activities
6. Schedule 6 - Environmental Reports: Environmental impact assessments, sustainability requirements, and mitigation measures
7. Schedule 7 - Form of Warranties: Standard forms of warranties and guarantees required for the development
Authors
Relevant legal definitions
Clauses
Relevant Industries
Relevant Teams
Relevant Roles
Find the exact document you need
Software Development Services Contract
A Singapore law-governed agreement for software sales and licensing, ensuring compliance with local technology and data protection regulations.
find out more
Property Development Contract
A Singapore-compliant agreement establishing terms between property owners and management companies for property maintenance and operations.
find out more
Business Development Contract
A Singapore-law governed agreement for the purchase of a bike through installment payments, with ownership retained by the seller until final payment.
find out more
Area Developer Agreement
A Singapore-compliant agreement establishing terms for repayment of outstanding debts in arrears.
find out more
Web Developer Contract
A Singapore-law governed agreement enabling software rebranding and distribution under a partner's brand name.
find out more
Real Estate Development Fee Agreement
A Singapore-law governed agreement for transferring real estate ownership between parties, incorporating local property legislation and transfer requirements.
find out more
Developer's Agreement
A bank's irrevocable payment undertaking governed by Singapore law and UCP 600, securing international trade transactions.
find out more
Freelance Web Development Contract
A Singapore-compliant document that outlines employment terms and conditions accompanying a job offer.
find out more
Redevelopment Agreement
A Singapore-compliant confidentiality agreement for healthcare employees, protecting patient and institutional data under local healthcare laws.
find out more
Coal Mine Development And Production Agreement
A Singapore-compliant agreement between divorcing spouses that establishes terms for asset division, maintenance, and family arrangements.
find out more
Joint Technology Development Agreement
A formal notice under Singapore law to end a real estate agent's engagement.
find out more
Design Development Agreement
A Singapore-law governed agreement establishing terms and conditions for dispatch services between a provider and client.
find out more
Revenue Sharing Joint Development Agreement
A Singapore-compliant legal document releasing parties from real estate-related claims and obligations.
find out more
Development And Manufacturing Agreement
An official employment verification document issued by Singapore employers, confirming an individual's work history and tenure with the organization.
find out more
Master Development Agreement
A Singapore-law governed agreement that documents the terms of sale between buyer and seller, establishing their rights and obligations.
find out more
Subdivision Agreement
A Singapore-compliant legal document combining vehicle sale transfer and payment terms agreement.
find out more
Prototype Development Agreement
A Singapore law-governed agreement between prospective spouses establishing financial arrangements and asset division before marriage.
find out more
Mine Development And Production Agreement
A Singapore-compliant legal document recording property owner's consent for specific property-related actions.
find out more
Freelance Developer Contract
A Singapore-law governed agreement between property owner and general contractor for construction projects, compliant with local building and safety regulations.
find out more
Joint Development Agreement Between Landowner And Builder
A Singapore-law governed agreement that structures the settlement of overdue payments between parties, including revised payment terms and interest calculations.
find out more
Performance And Development Agreement
A Singapore-compliant formal document verifying employment details and experience of a research assistant.
find out more
Market Development Agreement
A Singapore-law governed agreement between spouses establishing terms and commitments for marriage reconciliation.
find out more
Development Funding Agreement
A Singapore law-governed agreement establishing exclusive representation rights between a principal and representative, defining territorial scope and commercial terms.
find out more
Product Collaboration Agreement
A Singapore-law governed agreement protecting confidential information shared between individuals in a personal relationship.
find out more
Mutual Development Agreement
A Singapore-law governed agreement establishing terms for profit distribution between investors and business entities.
find out more
Site Development Agreement
A Singapore-law governed agreement establishing terms for software development partnerships, including IP rights and operational responsibilities.
find out more
Forward Funding Agreement
A formal document outlining terms for internal job transfers in Singapore, compliant with local employment laws.
find out more
Co Development Agreement
A formal legal notice under Singapore law demanding remedies for defamatory statements.
find out more
Incentive Agreement
A Singapore-law governed legal document that releases one party from liability for specified risks or potential damages.
find out more
Game Development Agreement
A Singapore-law governed agreement for HVAC system maintenance services, compliant with local building and safety regulations.
find out more
Research And Development Agreement
A formal resignation letter compliant with Singapore employment law and MOM guidelines, used to initiate voluntary termination of employment.
find out more
Agile Software Development Agreement
A Singapore law-governed contract documenting the terms and conditions for the sale and purchase of goods or assets between parties.
find out more
Project Development Agreement
A Singapore-compliant professional reference document from a mentor detailing a mentee's capabilities and development.
find out more
Product Development Agreement
A Singapore law-governed agreement establishing terms for ongoing supply relationships between suppliers and customers.
find out more
App Development Contract
A formal notice under Singapore law requesting early termination of a lease agreement.
find out more
Download our whitepaper on the future of AI in Legal
By providing your email address you are consenting to our Privacy Notice.
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
Our bank-grade security infrastructure undergoes regular external audits
We are ISO27001 certified, so your data is secure
Organizational security
You retain IP ownership of your documents
You have full control over your data and who gets to see it
Innovation in privacy:
Genie partnered with the Computational Privacy Department at Imperial College London
Together, we ran a £1 million research project on privacy and anonymity in legal contracts
Want to know more?
Visit our for more details and real-time security updates.
Read our Privacy Policy.