Construction Company Contracts are essential legal instruments used in the United States construction industry to formalize agreements between contractors and project owners. These contracts are particularly crucial when undertaking construction projects of any scale, from residential to commercial developments. The document serves as a comprehensive framework that addresses all aspects of the construction process, including project scope, payment structures, timeline commitments, and quality requirements. It is designed to comply with both federal regulations (such as OSHA standards, Davis-Bacon Act requirements) and state-specific construction laws, building codes, and licensing requirements. The contract type is specifically structured to protect all parties' interests while ensuring clear accountability and risk allocation throughout the project lifecycle. It includes provisions for changes, disputes, and project completion, making it a fundamental tool for project execution and risk management in the U.S. construction industry.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Your data doesn't train Genie's AI
You keep IP ownership of your docs
1. Parties: Identification of the contracting parties including full legal names, addresses, and registration details
2. Background: Context of the agreement and general purpose of the construction project
3. Definitions: Detailed definitions of terms used throughout the contract
4. Scope of Work: Detailed description of the construction work to be performed, including specifications and standards
5. Contract Price and Payment Terms: Total contract value, payment schedule, payment conditions, and invoicing procedures
6. Project Timeline: Project start date, completion date, milestones, and any liquidated damages for delays
7. Contractor Obligations: Specific responsibilities of the contractor including quality standards, materials, and workmanship
8. Client Obligations: Responsibilities of the client including site access, permits, and approvals
9. Safety Requirements: Safety protocols, OSHA compliance, and site safety management requirements
10. Insurance and Bonds: Required insurance coverage, bonds, and indemnification provisions
11. Changes and Variations: Procedures for handling change orders and variations to the scope of work
12. Warranties and Defects: Warranty terms, defect liability period, and remediation procedures
13. Termination: Conditions and procedures for contract termination by either party
14. Dispute Resolution: Procedures for resolving disputes, including mediation and arbitration provisions
15. General Provisions: Standard legal provisions including governing law, notices, and assignment rights
1. Environmental Compliance: Specific environmental requirements and compliance procedures, included when project has significant environmental impacts
2. Subcontractor Management: Rules and procedures for managing subcontractors, included when subcontracting is permitted
3. Equipment and Materials Storage: Requirements for on-site storage and security, included for projects with significant material storage needs
4. Site Investigation: Provisions regarding site condition investigations, included for projects with potential ground condition risks
5. Force Majeure: Specific provisions for unforeseen events, included based on project location and risk factors
6. Labor Requirements: Specific labor-related provisions, included for projects subject to Davis-Bacon Act or similar regulations
7. Quality Control Program: Detailed quality management requirements, included for complex or high-specification projects
8. Value Engineering: Provisions for cost optimization suggestions, included for large-scale projects
9. Commissioning: Requirements for testing and commissioning, included for mechanical/electrical installations
1. Schedule A - Scope of Work: Detailed technical specifications and drawings
2. Schedule B - Bill of Quantities: Itemized list of quantities and rates for the work
3. Schedule C - Project Timeline: Detailed project schedule with milestones and critical path
4. Schedule D - Payment Schedule: Detailed breakdown of payment terms and milestone payments
5. Schedule E - Site Information: Site plans, access points, and existing conditions
6. Schedule F - Required Insurance: Detailed insurance requirements and coverage limits
7. Schedule G - Key Personnel: List of key project personnel and their responsibilities
8. Schedule H - Equipment Schedule: List of major equipment to be used in the project
9. Schedule I - Quality Control Requirements: Detailed quality control procedures and standards
10. Appendix 1 - Forms and Ƶ: Standard forms for change orders, progress reports, and other project documents
Find the exact document you need
General Contractor And Subcontractor Agreement
U.S.-governed agreement between general contractor and subcontractor defining work scope, terms, and obligations in construction projects.
Download
General Contractor Contract With Subcontractor
U.S.-governed construction agreement between general contractor and subcontractor defining work scope, terms, and responsibilities.
Download
Standard Contractors Agreement
A legally binding U.S. agreement that establishes terms between a business and an independent contractor, ensuring compliance with federal and state regulations.
Download
Contract Agreement Between Owner And Contractor
A U.S. legal agreement defining terms and conditions between a property owner and construction contractor for building work.
Download
Home Contractor Agreement
A U.S. legal agreement between a homeowner and contractor defining terms for residential construction or renovation work.
Download
Contractor Warranty Agreement
A U.S.-compliant legal agreement defining a contractor's warranty terms and obligations for construction work or improvements.
Download
Collaboration Agreement With Builder
A U.S.-based legal agreement establishing terms and conditions between property owners/developers and builders for collaborative construction projects.
Download
Building Material Contract Agreement
A U.S.-governed agreement establishing terms for the supply of construction materials, including specifications, pricing, and delivery terms.
Download
Contractor Owner Agreement
A U.S.-governed legal agreement between a property owner and contractor defining project terms, responsibilities, and obligations.
Download
Agreement Between Two Parties For Construction Contract
A U.S.-governed bilateral construction contract defining project scope, terms, and obligations between property owner and contractor.
Download
Pre Construction Purchase Agreement
A U.S.-governed agreement for purchasing property before construction completion, outlining terms between buyer and developer.
Download
Agreement Between Builder And Contractor
A U.S.-governed contract defining the terms and conditions between a builder and contractor for construction services.
Download
New Construction Purchase Agreement
A U.S. legal agreement governing the purchase of newly constructed property, outlining terms between builder and buyer.
Download
Home Improvement Construction Contract
A U.S.-compliant contract between property owner and contractor for home improvement projects, outlining work scope, terms, and obligations.
Download
Collaboration Agreement For Construction Of Building
A U.S.-governed agreement establishing terms for multiple parties collaborating on a construction project.
Download
Construction Operating Agreement
A U.S.-governed legal agreement establishing terms and conditions for construction operations, including safety protocols and operational procedures.
Download
Construction Company Contracts
A U.S.-governed construction contract establishing terms, conditions, and obligations for construction projects, compliant with federal and state regulations.
Download
General Contractor Subcontractor Agreement
U.S.-governed agreement between general contractor and subcontractor defining work scope, payments, and responsibilities in construction projects.
Download
Landscape Contractor Contract
A U.S.-governed contract defining terms between landscape contractors and property owners for landscaping services and maintenance.
Download
Subcontract Agreement For Construction Work
A U.S.-governed agreement between contractor and subcontractor defining terms, conditions, and responsibilities for specified construction work performance.
Download
Owner Subcontractor Agreement
A U.S. legal agreement between property owner and subcontractor defining work scope, terms, and obligations under federal and state construction laws.
Download
Contract Between Builder And Client
A U.S.-governed contract establishing terms between a builder and client for construction services.
Download
Building Construction Contract Agreement
A U.S.-governed legal agreement between property owners and contractors defining terms and conditions for construction projects.
Download
Agreement Between Two Contractors
A U.S. legal agreement establishing terms and conditions between two independent contractors for collaborative work or services.
Download
Design And Construct Contract
A US-governed contract combining design and construction services under a single agreement between owner and design-build contractor.
Download
Design Build Contract
A U.S.-governed contract combining design and construction services under a single agreement, establishing responsibilities and requirements for integrated project delivery.
Download
Construction Labor Contract Agreement
A U.S.-compliant legal agreement establishing employment terms between construction contractors and workers, covering work scope, compensation, and safety requirements.
Download
Construction Collaboration Agreement
A U.S.-compliant legal agreement establishing terms for multiple parties to collaborate on a construction project.
Download
Agreement Between Land Owner And Builder
A U.S.-governed contract establishing terms between a land owner and builder for construction work on specified property.
Download
Letter Of Agreement For Construction Work
A U.S.-compliant legal document establishing terms between contractor and property owner for construction services.
Download
Management Building Contract
A U.S.-compliant legal agreement between property owner and construction manager defining project management services and responsibilities.
Download
Construction Work Agreement
A U.S.-governed legal agreement between a contractor and property owner establishing terms for construction services.
Download
Commercial Construction Agreement
A U.S.-governed contract between owner and contractor establishing terms for commercial construction projects.
Download
Owner Builder Agreement
A U.S. legal agreement establishing terms and conditions for property owners acting as their own general contractor in construction projects.
Download
General Contractor Contract With Owner
A U.S. construction contract between property owner and general contractor defining project terms, responsibilities, and obligations.
Download
Construction Labor Agreement
A U.S.-governed agreement establishing employment terms between construction contractors and workers, covering wages, hours, and working conditions.
Download
Home Builder Contract
A U.S.-compliant legal agreement between a builder and property owner for new home construction, specifying terms, conditions, and obligations.
Download
Building Construction Agreement
A U.S.-governed contract between property owner and contractor establishing terms for building construction projects.
Download
Builder Agreement
A U.S.-compliant legal agreement between a builder and property owner defining construction project terms and responsibilities.
Download
Residential Construction Contract
A U.S.-governed legal agreement between property owner and contractor for residential construction or renovation projects.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)