The Contract For Contractor And Homeowner is an essential legal instrument used in Pakistan's construction industry for residential projects. This document is specifically designed for situations where a homeowner engages a contractor for construction, renovation, or improvement works on their property. It encompasses crucial elements required under Pakistani law, including provisions from the Contract Act 1872, Building Control Ordinance, and relevant local government regulations. The agreement is particularly important as it protects both parties' interests by clearly defining scope, responsibilities, payment terms, and quality standards while ensuring compliance with local building codes and regulations. It's commonly used for both new construction projects and major renovations, providing a structured framework for project execution while incorporating necessary legal safeguards and dispute resolution mechanisms.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Your data doesn't train Genie's AI
You keep IP ownership of your docs
1. Parties: Identification and details of the homeowner and contractor, including full legal names, addresses, and contact information
2. Background: Brief context of the construction project and the parties' intention to enter into this agreement
3. Definitions: Key terms used throughout the contract defined for clarity and legal certainty
4. Scope of Work: Detailed description of the construction work to be performed, including specific tasks and deliverables
5. Contract Price and Payment Terms: Total contract value, payment schedule, and method of payment
6. Timeline and Completion: Project start date, completion date, and any milestone deadlines
7. Materials and Labor: Specifications regarding construction materials, quality standards, and labor requirements
8. Permits and Compliance: Responsibility for obtaining necessary permits and ensuring compliance with local building codes
9. Warranties and Guarantees: Contractor's warranties on workmanship and materials
10. Insurance and Liability: Required insurance coverage and allocation of risks between parties
11. Termination: Conditions and procedures for contract termination by either party
12. Dispute Resolution: Process for resolving disputes, including mediation or arbitration procedures
13. Governing Law: Specification of Pakistani law as governing law and relevant jurisdiction
14. Force Majeure: Provisions for unforeseen circumstances preventing contract performance
15. Notices: Method and addresses for official communications between parties
16. Entire Agreement: Confirmation that the contract represents the complete agreement between parties
1. Subcontractors: Terms regarding the engagement and management of subcontractors, used when subcontracting is anticipated
2. Environmental Protection: Specific environmental protection measures, required for projects with significant environmental impact
3. Site Security: Provisions for securing the construction site, relevant for high-value or sensitive locations
4. Utilities and Facilities: Terms regarding utility connections and temporary facilities, needed for major construction projects
5. Storage of Materials: Requirements for material storage on site, relevant for larger projects or limited site space
6. Quality Control Procedures: Detailed quality control processes, important for complex or high-end construction projects
7. Variations and Changes: Process for handling changes to scope or specifications, crucial for complex projects
8. Delay Damages: Liquidated damages for delays, relevant for time-sensitive projects
1. Schedule A - Detailed Scope of Work: Comprehensive breakdown of construction tasks, specifications, and requirements
2. Schedule B - Payment Schedule: Detailed payment terms, installments, and milestone-linked payments
3. Schedule C - Construction Timeline: Detailed project timeline including all major milestones and completion dates
4. Schedule D - Material Specifications: Detailed list of approved materials, brands, and quality standards
5. Schedule E - Drawings and Plans: Architectural drawings, structural plans, and other technical specifications
6. Schedule F - Safety Requirements: Safety protocols and requirements for the construction site
7. Schedule G - Insurance Requirements: Detailed insurance requirements including coverage types and amounts
8. Appendix 1 - Required Permits: List of all required permits and approvals needed for the project
9. Appendix 2 - Quality Control Checklist: Detailed checklist for quality control inspections and approvals
Find the exact document you need
Agreement Between Builder And Labour Contractor
A Pakistani law-governed agreement between builders and labor contractors defining terms for construction workforce services, including responsibilities, payments, and compliance requirements.
Download
Basic General Contractor Agreement
A Pakistani law-governed agreement between property owners and general contractors defining terms and conditions for construction projects.
Download
Cleaning Subcontractor Contract
A Pakistani law-governed agreement between a main contractor and cleaning subcontractor defining terms for cleaning service provision and operational requirements.
Download
Contract Between Employer And Contractor
A Pakistani law-governed agreement establishing terms and conditions between an employer and contractor, defining work scope, payments, and mutual obligations.
Download
Electrical Contractor Agreement
A Pakistani law-governed agreement between client and electrical contractor for electrical services, incorporating local regulatory requirements and industry standards.
Download
Contractor Service Contract
A Pakistani law-governed agreement establishing terms and conditions between a client and an independent contractor for the provision of specific services.
Download
Labour Contract Form
A legally binding employment agreement compliant with Pakistani labor laws that establishes terms and conditions between employer and employee.
Download
Contractor Agreement For House (Construction)
A Pakistani law-governed agreement between property owner and contractor for residential construction, detailing project scope, terms, and mutual obligations.
Download
Contractor Deposit Agreement
A Pakistan-compliant agreement governing contractor security deposits, their maintenance, and return conditions.
Download
Building Construction Labour Contract Agreement
A standardized labor contract agreement for construction workers in Pakistan, ensuring compliance with local labor laws and construction regulations.
Download
Home Contractor Contract
A Pakistani law-governed contract between homeowner and contractor for residential construction/renovation work, outlining project terms, obligations, and deliverables.
Download
Standard Independent Contractor Contract
A Pakistani law-governed agreement establishing an independent contractor relationship, defining services, payments, and obligations while ensuring legal compliance.
Download
Real Estate Contractor Agreement
A Pakistani law-governed agreement between property owner and contractor for construction works, detailing project terms, conditions, and regulatory compliance requirements.
Download
Agreement Between Owner And Electrical Contractor
A comprehensive contract governing electrical works between property owners and contractors in Pakistan, ensuring compliance with local regulations and safety standards.
Download
Standard Contractor Contract
A Pakistani law-governed agreement establishing terms and conditions between a company and an independent contractor, ensuring legal compliance while defining service scope and relationship parameters.
Download
Generic Contractor Agreement
A Pakistan-law compliant agreement establishing terms and conditions between a hiring entity and an independent contractor, covering work scope, payments, and legal obligations.
Download
Independent Service Contract
A Pakistani law-governed agreement establishing terms and conditions between an independent service provider and client, defining service scope, payments, and contractual obligations.
Download
Agreement Between Company And Labour Contractor
A legal agreement under Pakistani law governing the relationship between a company and labor contractor for workforce provision and management.
Download
Construction Agreement Form
A comprehensive construction agreement template compliant with Pakistani law, establishing terms and conditions between contractors and clients for construction projects.
Download
Freelance Contractor Agreement
A Pakistani law-compliant agreement establishing terms and conditions between a business and an independent contractor.
Download
Simple Subcontractor Agreement
A Pakistani law-governed agreement establishing terms and conditions between a main contractor and subcontractor for delegated work or services.
Download
Residential Contractor Agreement
A Pakistani law-governed agreement between property owner and contractor for residential construction works, detailing project scope, terms, and obligations.
Download
Labour Hire Contract
A Pakistani law-compliant agreement establishing terms for labor hire arrangements between a labor hire company, worker, and client company.
Download
Consulting Agreement Contract
A Pakistani law-governed agreement establishing terms and conditions between a consultant and client for professional consulting services.
Download
Construction Contractor Contract
A Pakistani law-governed agreement between a construction contractor and project owner, defining construction project terms, obligations, and execution requirements.
Download
Startup Contractor Agreement
A Pakistan-law governed contractor agreement for startups engaging independent professionals, ensuring legal compliance while maintaining startup-appropriate flexibility.
Download
Standard Builders Contract
A Pakistani law-governed construction agreement establishing rights and obligations between employer and contractor for building projects, aligned with local regulations and industry standards.
Download
Percentage Agreement Contract
A Pakistani law-governed agreement establishing percentage-based commercial relationships, detailing calculation methods and payment terms for revenue or profit sharing arrangements.
Download
Part Time Contractor Agreement
Pakistani law-compliant agreement establishing terms and conditions for part-time contractor engagement, including scope, payment, and legal obligations.
Download
Independent Employment Agreement
A Pakistani law-governed agreement establishing an independent contractor relationship between a company and a service provider, defining services, compensation, and compliance requirements.
Download
Home Remodel Contract
A Pakistani law-governed contract for home renovation projects between homeowners and contractors, outlining construction terms and obligations.
Download
Housekeeping Services Agreement Contract
A Pakistani law-governed agreement establishing terms and conditions for professional housekeeping services, including service scope, requirements, and compliance with local regulations.
Download
General Contract Agreement Between Two Parties
A standard bilateral contract agreement compliant with Pakistani law, establishing terms and conditions for business relationships between two parties.
Download
Construction Service Contract
A Pakistani law-governed agreement establishing terms and conditions for construction services between contractor and client, ensuring regulatory compliance and project delivery standards.
Download
Confidentiality Agreement For Contractors
A Pakistan-law governed agreement establishing confidentiality obligations between a company and its contractors, protecting sensitive business information and trade secrets.
Download
Agreement For Construction Of House
A Pakistani law-governed agreement establishing terms and conditions for residential house construction, including specifications, timelines, and payment terms.
Download
Agreement Between Contractor And Principal Employer
A Pakistan-law governed agreement establishing terms and conditions between a Principal Employer and Contractor for professional services.
Download
Truck Driver Contractor Agreement
A Pakistani law-governed agreement establishing terms and conditions between a company and an independent truck driver contractor, covering operational, safety, and compliance requirements.
Download
Contract Agreement Between Contractor And Client
A Pakistani law-governed agreement establishing terms and conditions between a client and contractor for professional services or project delivery.
Download
Hourly Independent Contractor Agreement
A Pakistani law-governed agreement establishing terms and conditions for hourly-based independent contractor services.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)