The Home Repair Contract is essential for documenting agreements between contractors and homeowners in Austria for residential repair and maintenance work. This document is specifically designed to comply with Austrian legal requirements, including the ABGB (Austrian Civil Code) and KSchG (Consumer Protection Act). It should be used whenever a contractor undertakes home repair or renovation work for a homeowner, regardless of the project size. The contract includes crucial elements such as detailed work specifications, pricing, timeline, warranties, and both parties' obligations. It incorporates consumer protection provisions, building regulation compliance requirements, and necessary safeguards for both the contractor and homeowner. The document is structured to facilitate clear understanding and prevent disputes while ensuring legal enforceability under Austrian law.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification of the contractor and homeowner, including full legal names, addresses, and registration numbers (if applicable)
2. Background: Brief context of the repair needs and confirmation of contractor's qualifications
3. Definitions: Key terms used throughout the contract including 'Works', 'Completion Date', 'Materials', 'Specifications'
4. Scope of Work: Detailed description of the repair works to be performed, including specific tasks and exclusions
5. Contract Price and Payment Terms: Total cost, payment schedule, and method of payment
6. Timeline: Start date, completion date, and any interim milestones
7. Materials and Equipment: Specifications of materials to be used, quality standards, and responsibility for procurement
8. Contractor's Obligations: Professional standards, safety requirements, licenses, permits, and workspace management
9. Client's Obligations: Access to premises, utilities provision, and necessary cooperation
10. Warranties: Statutory and additional warranties on workmanship and materials
11. Insurance and Liability: Required insurance coverage and allocation of risks
12. Termination: Grounds for termination and consequences
13. Governing Law: Confirmation of Austrian law application and jurisdiction
1. Subcontractors: Include when the contractor may need to engage subcontractors, specifying approval requirements and liability
2. Variations: Include for larger projects where changes to scope may be likely, detailing the process for requesting and approving changes
3. Force Majeure: Include for longer-term projects to address unforeseen circumstances preventing performance
4. Dispute Resolution: Include for larger projects, specifying mediation or arbitration procedures
5. Intellectual Property: Include when custom designs or plans are involved
6. Data Protection: Include when significant personal data processing is involved
7. Environmental Requirements: Include when work involves hazardous materials or specific environmental considerations
1. Schedule 1 - Detailed Scope of Works: Comprehensive technical specifications of the repair work to be performed
2. Schedule 2 - Payment Schedule: Detailed breakdown of payments, including timing and conditions for each payment
3. Schedule 3 - Timeline: Detailed project schedule with milestones and completion dates
4. Schedule 4 - Materials Specifications: Detailed list of materials to be used, including brands, qualities, and quantities
5. Appendix A - Required Permits: Copies of or references to necessary building permits and authorizations
6. Appendix B - Insurance Certificates: Copies of required insurance policies
7. Appendix C - Warranty Certificates: Manufacturer warranties for materials and equipment
Authors
Relevant legal definitions
Clauses
Relevant Industries
Construction
Home Improvement
Building Maintenance
Interior Design
Residential Real Estate
Property Management
Home Services
Construction Materials
Insurance
Professional Services
Relevant Teams
Legal
Operations
Construction
Project Management
Quality Assurance
Customer Service
Procurement
Compliance
Risk Management
Business Development
Technical Services
Contract Administration
Relevant Roles
Construction Manager
Project Manager
Contract Administrator
Legal Counsel
General Contractor
Procurement Manager
Quality Control Inspector
Site Supervisor
Risk Manager
Compliance Officer
Business Development Manager
Operations Manager
Customer Relations Manager
Technical Director
Estimator
Find the exact document you need
Rental Forms For Landlord
Austrian-law compliant rental agreement template for landlords, incorporating essential elements required by the Mietrechtsgesetz and related legislation.
find out more
Contract For House (Construction)
An Austrian law-governed contract setting out terms and conditions for residential house construction, including scope, payments, timeline, and quality standards.
find out more
Website Agreement Contract
An Austrian law-compliant agreement governing website usage terms, incorporating both national and EU regulations for website operations and user interactions.
find out more
Business To Business Contract
Austrian law-compliant B2B contract template for commercial transactions between business entities, incorporating UGB and ABGB requirements.
find out more
Service Level Guarantee
An Austrian law-governed agreement defining guaranteed service performance levels, measurements, and remedies for service delivery.
find out more
Notarial Contract
An Austrian law-governed formal contract authenticated by a notary, providing enhanced legal certainty for significant transactions.
find out more
Labor Agreement
An Austrian-law governed employment contract establishing the employment relationship and key terms between employer and employee.
find out more
Website Maintenance Agreement
An Austrian law-governed agreement for website maintenance services, defining maintenance scope, service levels, and obligations of both parties.
find out more
Client Agreement Form
An Austrian law-governed agreement establishing terms and conditions between service providers and their clients, ensuring compliance with Austrian legal requirements.
find out more
IT Service Level Agreement
Austrian-law governed IT Service Level Agreement specifying terms, conditions, and performance metrics for IT service delivery.
find out more
Supply Agreement Contract
An Austrian law-governed agreement establishing terms for regular supply of goods or materials, compliant with ABGB and UGB requirements.
find out more
Reservation Contract
An Austrian law-compliant contract establishing terms and conditions for reserving goods, services, or properties, including reservation fees, periods, and conversion terms.
find out more
Operation And Maintenance Contract
An Austrian law-governed agreement for facility operations and maintenance services, defining service provider and owner obligations, performance standards, and commercial terms.
find out more
Framework Contract In Procurement
An Austrian law-governed framework agreement establishing terms for ongoing procurement of goods, services, or works between a contracting authority and supplier(s).
find out more
Facility Letter
An Austrian law-governed document issued by a financial institution setting out the terms and conditions of a credit facility offer to a borrower.
find out more
Enterprise Subscription Agreement
An Austrian law-governed agreement for enterprise-level subscription services, covering service terms, access rights, and compliance requirements.
find out more
Development Services Agreement
An Austrian law-governed agreement establishing terms for development services delivery, including scope, deliverables, and IP rights.
find out more
Customer Protection Agreement
An Austrian law-governed agreement establishing consumer protection measures and business obligations in accordance with Austrian and EU consumer protection regulations.
find out more
Clearing Agreement
An Austrian law-governed agreement establishing clearing arrangements between financial market participants, setting out terms for clearing services, risk management, and regulatory compliance.
find out more
Admission Agreement
An Austrian law-governed agreement between an educational institution and student establishing terms for program admission and enrollment.
find out more
Transfer Contract
An Austrian law-governed agreement facilitating the transfer of ownership or rights in assets between parties, subject to Austrian Civil Code requirements.
find out more
Shared Services Agreement
An Austrian law-governed agreement establishing the framework for shared services between organizations, covering service delivery, performance standards, and compliance requirements.
find out more
Installation Agreement
Austrian law-governed agreement for equipment or system installation, covering technical specifications, warranties, and acceptance criteria.
find out more
Payment Settlement Agreement
An Austrian law-governed agreement that establishes terms for settling payment obligations between parties, including settlement amount, payment terms, and mutual releases.
find out more
Web Development Agreement
An Austrian law-governed agreement establishing terms and conditions for web development services, including project scope, deliverables, and legal compliance requirements.
find out more
Personal Services Contract
Austrian law-compliant Personal Services Contract for independent professionals providing services to organizations.
find out more
Volunteer Agreement
Austrian law-compliant Volunteer Agreement template defining rights and responsibilities in voluntary engagements.
find out more
Home Construction Contract
An Austrian law-governed contract for residential construction projects, compliant with ABGB and consumer protection regulations.
find out more
Home Repair Contract
Austrian-law governed Home Repair Contract establishing terms for residential repair services, compliant with ABGB and consumer protection regulations.
find out more
Data Processing Agreement
An Austrian law-governed Data Processing Agreement ensuring GDPR compliance for personal data processing activities between controller and processor.
find out more
Landscape Contract
An Austrian law-governed contract for landscape construction and maintenance services, defining scope, terms, and responsibilities between contractor and client.
find out more
Equipment Rental Form
Austrian law-compliant Equipment Rental Form establishing terms and conditions for equipment rental, suitable for both B2B and B2C use.
find out more
Simple Consulting Agreement
An Austrian law-governed consulting agreement template for establishing professional consulting relationships, compliant with ABGB and GDPR requirements.
find out more
Business Consulting Agreement
An Austrian law-governed agreement establishing terms and conditions between a business consultant and client for professional consulting services.
find out more
Rental Guarantor Form
An Austrian law-compliant document establishing a third-party guarantee for rental obligations, detailing the guarantor's responsibilities and liability limits.
find out more
IT Service Agreement
An Austrian law-governed agreement establishing terms and conditions for IT service provision, including service levels, data protection, and operational requirements.
find out more
Cleaning Business Contract
An Austrian law-governed agreement establishing terms and conditions for professional cleaning services, including service specifications, performance standards, and regulatory compliance.
find out more
Letter For Payment Agreement
An Austrian law-governed formal letter establishing debt repayment terms and conditions between creditor and debtor, providing a legally binding payment commitment.
find out more
Standard Service Agreement
An Austrian law-governed Standard Service Agreement establishing terms and conditions between service provider and client.
find out more
Colocation Agreement
An Austrian law-governed agreement for data center space and services provision, covering facility usage, technical specifications, and operational requirements.
find out more
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)