Construction Company Contracts are essential legal documents used in Ireland to establish binding agreements between construction companies and project owners/employers. These contracts are specifically designed to comply with Irish construction law, including the Construction Contracts Act 2013, Building Control Acts, and Safety, Health and Welfare at Work Regulations. They are utilized when undertaking construction projects of various scales and complexities, from commercial buildings to residential developments. The document incorporates mandatory payment practices, dispute resolution procedures, and safety requirements specific to Irish law, while also addressing project specifications, timelines, quality standards, and risk allocation. These contracts are crucial for protecting all parties' interests and ensuring clear understanding of responsibilities throughout the construction process.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification of the contracting parties including full legal names, addresses, and company registration numbers
2. Background: Context of the agreement and brief description of the construction project
3. Definitions and Interpretation: Detailed definitions of terms used throughout the contract and interpretation rules
4. Scope of Works: Detailed description of the construction works to be performed
5. Contract Sum and Payment Terms: Amount payable, payment schedule, and payment procedures compliant with Construction Contracts Act 2013
6. Project Timeline: Commencement date, completion date, and key milestone dates
7. Contractor Obligations: Primary responsibilities and obligations of the contractor
8. Employer Obligations: Primary responsibilities and obligations of the employer
9. Health and Safety: Safety requirements and compliance with Safety, Health and Welfare at Work Regulations
10. Insurance and Indemnity: Required insurance coverage and indemnification provisions
11. Quality and Standards: Quality standards, inspections, and compliance requirements
12. Variations: Procedures for handling changes to the scope of work
13. Termination: Grounds and procedures for contract termination
14. Dispute Resolution: Procedures for resolving disputes including mediation and arbitration
15. General Provisions: Standard boilerplate clauses including notices, governing law, and entire agreement
1. Design Responsibilities: Include when contractor has design obligations in addition to construction
2. Environmental Management: Include for projects with significant environmental impact considerations
3. Phased Completion: Include when project involves separate completion phases
4. Subcontracting: Include detailed subcontracting terms when subcontracting is permitted
5. Intellectual Property: Include when design or innovative construction methods are involved
6. Performance Bond: Include when project requires performance security
7. Retention: Include specific retention provisions for larger projects
8. Liquidated Damages: Include when specific damages for delay are to be pre-agreed
9. Site Conditions: Include detailed site-specific provisions for complex sites
10. Materials and Plant: Include specific provisions about supply and storage of materials when significant
1. Schedule 1 - Project Specifications: Detailed technical specifications of the works
2. Schedule 2 - Contract Drawings: List and copies of all relevant construction drawings
3. Schedule 3 - Price Schedule: Detailed breakdown of the contract sum including bill of quantities
4. Schedule 4 - Programme of Works: Detailed project timeline and construction schedule
5. Schedule 5 - Insurance Requirements: Specific insurance types and coverage levels required
6. Schedule 6 - Key Personnel: List of key personnel from both parties and their roles
7. Schedule 7 - Site Information: Site details, access arrangements, and existing conditions
8. Schedule 8 - Forms and Certificates: Template forms for certificates, applications, and notices
9. Schedule 9 - Quality Assurance Requirements: Specific quality standards and testing requirements
10. Appendix A - Health and Safety Requirements: Detailed health and safety specifications and procedures
Authors
Relevant legal definitions
Clauses
Relevant Industries
Commercial Construction
Residential Development
Industrial Construction
Infrastructure Development
Healthcare Construction
Educational Facilities
Retail Construction
Hospitality Construction
Public Works
Energy and Utilities
Transportation
Agricultural Construction
Sports and Recreation Facilities
Relevant Teams
Legal
Operations
Commercial
Finance
Procurement
Health and Safety
Project Management
Risk Management
Compliance
Construction Operations
Contract Administration
Technical Services
Relevant Roles
Construction Manager
Project Director
Contract Manager
Legal Counsel
Quantity Surveyor
Site Manager
Commercial Director
Risk Manager
Procurement Manager
Operations Director
Health and Safety Officer
Project Engineer
Financial Controller
Compliance Officer
Business Development Manager
Find the exact document you need
Renovation Contract Agreement
An Irish law-governed agreement setting out terms and conditions for property renovation works between a property owner and contractor.
find out more
Electrical Contractor Agreement
An Irish law-governed agreement between an electrical contractor and client for electrical installation, maintenance, or repair services, ensuring compliance with Irish electrical safety standards and regulations.
find out more
Basic Contractor Agreement
An Irish law-governed agreement establishing the terms and conditions between a company and an independent contractor, ensuring clear definition of services and maintaining contractor status.
find out more
Agreement To Rescind Contract
An Irish law-governed agreement that formally terminates an existing contract by mutual consent of the parties.
find out more
Simple Building Contract
An Irish law-governed building contract for small to medium construction projects, establishing rights and obligations between property owners and contractors.
find out more
Construction Company Contract
Irish construction company contract template compliant with local construction laws and regulations, suitable for various construction projects in Ireland.
find out more
Builder Client Contract
An Irish law-governed contract between a builder and client defining construction works, payments, and obligations under Irish construction regulations.
find out more
Labour Contract Form
Standard Irish labour contract outlining employment terms and conditions in compliance with Irish employment law.
find out more
Short Independent Contractor Agreement
An Irish law-governed short-form agreement for engaging independent contractors, balancing legal compliance with practical business needs.
find out more
Contractor Work Contract
An Irish law-governed agreement establishing the terms and conditions between a client and an independent contractor, defining services, payments, and obligations while maintaining contractor independence.
find out more
Indemnity Agreement (Construction)
Irish law construction indemnity agreement establishing risk allocation and protection mechanisms between construction project parties.
find out more
Indemnification Agreement (Construction)
An Irish law-governed agreement establishing indemnification obligations and risk allocation between parties in construction projects.
find out more
Contractor Contract Agreement
An Irish law-governed agreement establishing terms and conditions between a company and an independent contractor, ensuring clear definition of services, payments, and obligations.
find out more
Construction Contract Between Owner And Contractor
An Irish law-governed construction contract between property owner and contractor, compliant with the Construction Contracts Act 2013 and Irish building regulations.
find out more
Non Compete With Independent Contractor
An Irish law-compliant Non-Compete Agreement for independent contractors, protecting business interests while ensuring reasonable restrictions.
find out more
Exclusive Subcontractor Agreement
An Irish law-governed agreement establishing exclusive subcontracting arrangements between a main contractor and subcontractor, defining service delivery and compliance requirements.
find out more
General Contractor Contract Agreement
Irish law-governed construction agreement between an employer and general contractor, compliant with Construction Contracts Act 2013 and Irish building regulations.
find out more
Short Form Contractor Agreement
An Irish law-governed contractor agreement establishing key terms for independent contractor engagements while ensuring compliance with Irish legal requirements.
find out more
Cleaning Contractor Agreement
An Irish law-governed agreement between a client and cleaning contractor establishing terms for professional cleaning services provision.
find out more
House Renovation Contract
An Irish law-governed contract establishing terms and conditions for house renovation works between property owners and contractors.
find out more
Freelance Contractor Agreement
An Irish law-governed agreement establishing the terms and conditions between a company and an independent contractor, defining services, payments, and mutual obligations.
find out more
Subcontractor Service Agreement
An Irish law-governed agreement establishing terms and conditions between a contractor and subcontractor for service provision.
find out more
Sole Trader Contract
An Irish law-governed contract template for engaging sole traders as independent contractors, ensuring proper business relationship structure and regulatory compliance.
find out more
Simple Payment Agreement Contract
An Irish law-governed agreement establishing payment terms, schedules, and obligations between parties, with enforcement mechanisms under Irish commercial law.
find out more
Labour Hire Contract
An Irish law-governed Labour Hire Contract establishing terms between a labour hire agency, worker, and host employer, ensuring compliance with Irish employment legislation.
find out more
Labour Hire Agreement
An Irish law-governed agreement between a labour hire agency and client company for the provision of temporary workers, ensuring compliance with Irish employment legislation.
find out more
Driver Contractor Agreement
An Irish law-governed agreement between a company and an independent driver contractor, establishing terms for transportation services and regulatory compliance.
find out more
Domestic Subcontract Agreement
An Irish law-governed agreement between main contractor and subcontractor for residential construction works, incorporating key requirements of Irish construction legislation.
find out more
Contractor Service Agreement
An Irish law-governed agreement establishing terms and conditions between a company and an independent contractor for the provision of specific services.
find out more
Consulting Agreement Contract
An Irish law-governed agreement establishing the terms and conditions between a client and consultant for professional consulting services.
find out more
Self Employed Consultant Agreement
An Irish law-governed agreement establishing the terms and conditions between a client and a self-employed consultant, defining services, payments, and professional obligations.
find out more
Salon Contract For Employees
An Irish law-governed employment contract for salon staff, outlining terms, conditions, and industry-specific requirements for beauty and wellness professionals.
find out more
Part Time Contractor Agreement
An Irish law-governed agreement establishing terms and conditions for part-time contractor engagement, defining services, payments, and legal obligations.
find out more
Independent Sales Contract
An Irish law-governed agreement establishing terms between a company and independent sales agent, including commission structures and territorial rights.
find out more
Home Remodel Contract
An Irish law-governed contract for home renovation projects, establishing terms between homeowners and contractors while ensuring compliance with Irish construction regulations.
find out more
Framework Agreement Contract
An Irish law-governed agreement establishing terms for ongoing commercial relationships and future call-off contracts.
find out more
Confidentiality Agreement For Independent Contractors
Irish law-compliant confidentiality agreement for independent contractors, incorporating GDPR and local data protection requirements.
find out more
Binding Agreement Contract
An Irish law-governed binding agreement that establishes legal terms and conditions between parties, ensuring enforceability and compliance with Irish legal requirements.
find out more
Electrical Contract Form
An Irish-law electrical contract form for electrical installation and maintenance works, compliant with Irish safety regulations and construction laws.
find out more
Subcontractor Contract Form
An Irish law-governed agreement establishing terms and conditions between a main contractor and subcontractor for the provision of specified works or services.
find out more
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)